Effective: February 23, 2026
These Terms and Conditions govern your use of the website and services provided by Super Flooring & Interior. By accessing our website or engaging with our services, you agree to comply with and be bound by these terms. If you do not agree, please do not use our website or services.
Super Flooring & Interior provides flooring solutions and interior-related services, including consultation, supply, and installation. All service details, pricing, and timelines are discussed and agreed upon prior to project execution.
By using our website, you agree that:
We reserve the right to restrict or terminate access if misuse is detected.
All prices shared are indicative unless stated otherwise. Final pricing may vary based on material selection, site conditions, customization, and project scope. Quotations are valid for a limited period as specified at the time of issue.
Orders are confirmed only after mutual agreement and advance payment (if applicable). Payment terms, milestones, and modes are communicated before project initiation. Delays in payment may result in project delays or suspension of services.
Order cancellations must be communicated in writing. Refunds, if applicable, will be processed after deducting costs already incurred. Custom-made or installed materials are generally non-refundable.
Timelines are estimated and may vary due to site conditions, material availability, or unforeseen circumstances. Super Flooring & Interior is not liable for delays caused by factors beyond reasonable control.
All website content, including text, images, logos, designs, and layouts, is the property of Super Flooring & Interior and may not be copied, reproduced, or used without prior written permission.
Super Flooring & Interior shall not be held liable for:
Our liability, if any, shall be limited to the value of the services provided.
Our website may contain links to third-party websites for reference purposes. We do not control or take responsibility for the content, policies, or practices of these external websites.
These Terms and Conditions shall be governed and interpreted in accordance with the laws of India. Any disputes shall be subject to the jurisdiction of the courts in Delhi, India.
Super Flooring & Interior reserves the right to modify these Terms and Conditions at any time without prior notice. Continued use of the website or services constitutes acceptance of the updated terms.
For any questions regarding these Terms and Conditions, please contact:
Phone: +91-9999886939 / +91-9899633119
Email: superfloorings1@gmail.com
Address: 210, Shivam House Commercial Complex, Near Milan Cinema, Karampura, Delhi – 110015, India